Last updated: April 2026
By engaging VisualNest for any service — including web design, development, SEO, social media, PPC, or any other digital service — you agree to these Terms of Service. These terms form a legally binding agreement between you ("the Client") and VisualNest ("we", "us").
We will provide the services agreed upon in a written proposal or statement of work. Any changes to the agreed scope must be agreed in writing. Additional scope may be subject to additional charges.
Project fees are outlined in each individual proposal. A deposit (typically 50%) is required before work commences. The remaining balance is due upon project completion and before the final deliverables are transferred. Late payments may incur interest at 8% above the Bank of England base rate, in accordance with the Late Payment of Commercial Debts Act 1998.
Upon receipt of full payment, all final deliverables (website files, design assets, code) become the property of the Client. VisualNest retains the right to display completed work in our portfolio unless otherwise agreed in writing. Any third-party assets (fonts, stock images, plugins) remain subject to their respective licences.
Our proposals include a specified number of revision rounds. Additional revisions beyond the agreed number will be charged at our standard hourly rate. Client approval at each project milestone is required before proceeding to the next stage.
The Client agrees to provide all necessary content, materials, and feedback in a timely manner. Delays caused by the Client may affect project timelines and delivery dates. VisualNest is not responsible for project delays caused by late or incomplete provision of materials.
We warrant that our work will be of professional quality and delivered with reasonable skill and care. Our total liability in any circumstance is limited to the total fees paid for the specific project in question. We are not liable for indirect or consequential losses.
Either party may terminate an engagement with 14 days written notice. In the event of termination, the Client is liable for all work completed up to the date of termination. Deposits are non-refundable once work has commenced.
These terms are governed by the laws of England and Wales. Any disputes will be subject to the exclusive jurisdiction of the courts of England and Wales.
For any questions regarding these terms, contact info@visualnest.tech.